SEARCH SITE
VIRGINIA LAW PORTAL
- Code of Virginia
- Virginia Administrative Code
- Constitution of Virginia
- Charters
- Authorities
- Compacts
- Uncodified Acts
- RIS Users (account required)
SEARCHABLE DATABASES
- Bills & Resolutions
session legislation - Bill Summaries
session summaries - Reports to the General Assembly
House and Senate documents - Legislative Liaisons
State agency contacts
ACROSS SESSIONS
- Subject Index: Since 1995
- Bills & Resolutions: Since 1994
- Summaries: Since 1994
Developed and maintained by the Division of Legislative Automated Systems.
2020 SESSION
HB 680 Virginia Public Procurement Act; information technology project services contracts, behind schedule.
Introduced by: Dave A. LaRock | all patrons ... notes | add to my profiles
SUMMARY AS INTRODUCED:
Virginia Public Procurement Act; information technology project services contracts; behind schedule; verification of work. Requires that all state agencies include in every written contract for information technology project services contracts provisions that the agency is not required to pay for hours worked on a computer and billed by the hour on a project that (i) is more than one year behind on any scheduled contract performance dates or actual completion dates or (ii) has costs in excess of $1 million over the initial term of the contract, unless such hourly work is verified as legitimate by automatic billing verification software meeting certain standards. Any data collected by automatic billing verification software is considered accounting records belonging to the contractor; however, no contractor is permitted to sell or transfer such data or use it for any purpose or in any manner other than to verify and manage the hours worked on the associated contract and billed to the agency. The bill exempts from the contract provision and data collection requirement any (i) contracts (a) between state agencies, (b) with any law-enforcement agency, or (c) with any agency that is the custodian of criminal justice information as defined in the Federal Bureau of Investigation's Criminal Justice Information Services Division's Security Policy and (ii) work performed (a) by a state employee or (b) on a state-owned device.
FULL TEXT
HISTORY
- 01/06/20 House: Prefiled and ordered printed; offered 01/08/20 20103004D
- 01/06/20 House: Referred to Committee on General Laws
- 01/17/20 House: Assigned GL sub: Open Government/Procurement
- 01/28/20 House: Subcommittee recommends laying on the table (6-Y 2-N)
- 02/11/20 House: Left in General Laws